Terms of Service

1. Acceptance of Terms

These Terms of Service ("Terms") constitute a legally binding agreement between you ("Customer," "Client," or "you") and OMNIMAX LLC ("Company," "we," "us," or "our"). By requesting a quote, scheduling a consultation, or engaging our services, you acknowledge that you have read, understood, and agree to be bound by these Terms.

If you do not agree with any part of these Terms, please do not use our services. These Terms apply to all construction, roofing, remodeling, restoration, and related services provided by OMNIMAX LLC.

2. Services Provided

OMNIMAX LLC provides the following services in Nevada:

• Residential and commercial roofing installation, repair, and replacement
• General construction and remodeling services
• Kitchen and bathroom renovations
• Fire and water damage restoration
• Insurance claim assistance and consultation
• Emergency repair services
• Property inspections and assessments

All services are subject to availability, licensing requirements, and applicable local regulations. We reserve the right to decline any project that falls outside our expertise or licensing scope.

3. Estimates and Contracts

Free Estimates

We provide free estimates for most services. Estimates are based on visual inspection and information provided by the customer. Final pricing may vary based on actual conditions discovered during work.

Written Contracts

All work exceeding $500 will be governed by a written contract that includes:

• Detailed scope of work and materials specifications
• Project timeline and completion dates
• Total cost breakdown and payment schedule
• Warranty terms and conditions
• Change order procedures

4. Payment Terms

Payment Schedule

• Deposit: A deposit may be required before work begins, not to exceed 10% of the total contract value or $1,000, whichever is less
• Progress Payments: Payments are due based on work completion milestones as outlined in the contract
• Final Payment: Due upon satisfactory completion of all work and customer approval
• Emergency Services: Payment due within 30 days of service completion

Accepted Payment Methods

We accept cash, checks, credit cards, and bank transfers. A convenience fee may apply to credit card transactions. Late payments may incur interest charges as permitted by Nevada law.

5. Warranties and Guarantees

Workmanship Warranty

OMNIMAX LLC provides a comprehensive workmanship warranty on all completed projects:

• Roofing Work: 5-year warranty on workmanship, material warranties as per manufacturer
• Construction/Remodeling: 2-year warranty on workmanship
• Repairs: 1-year warranty on repair work
• Emergency Services: 90-day warranty on emergency repairs

Warranty Limitations

Warranties do not cover damage caused by acts of nature, normal wear and tear, improper maintenance, or modifications made by others. Warranty claims must be reported in writing within 30 days of discovery.

6. Insurance and Liability

Our Insurance Coverage

OMNIMAX LLC maintains comprehensive insurance coverage including:

• General liability insurance ($2,000,000 per occurrence)
• Workers' compensation insurance
• Professional liability insurance
• Bonding as required by law

Limitation of Liability

Our liability is limited to the contract value of the specific work performed. We are not liable for indirect, consequential, or punitive damages. Customer is responsible for protecting personal property and ensuring adequate homeowner's insurance coverage.

7. Customer Responsibilities

To ensure successful project completion, customers agree to:

• Provide accurate information about property conditions and requirements
• Obtain necessary permits (unless specified in contract that we will obtain them)
• Ensure safe access to work areas
• Remove or protect personal property in work areas
• Provide utilities (water, electricity) as needed for work completion
• Make timely payments according to the agreed schedule
• Communicate any concerns or changes promptly

8. Cancellation and Changes

Customer Cancellation Rights

Customers may cancel contracts within 3 business days of signing (Nevada's "cooling-off" period) for a full refund of any deposits paid. After this period, cancellation terms are as follows:

• Before work begins: Refund of deposit minus administrative costs (maximum $200)
• After work begins: Payment due for work completed plus materials ordered
• Emergency services: No cancellation once work has commenced

Change Orders

Any changes to the original scope of work must be documented in writing and signed by both parties. Additional costs and time extensions will be clearly outlined before proceeding with changes.

9. Dispute Resolution

Informal Resolution

We encourage customers to contact us directly to resolve any concerns. Most issues can be resolved through open communication and good faith efforts.

Formal Dispute Resolution

If informal resolution is unsuccessful, disputes will be resolved through binding arbitration in accordance with the rules of the American Arbitration Association. The arbitration will take place in Clark County, Nevada, and Nevada law will govern the proceedings.

10. Force Majeure

OMNIMAX LLC is not liable for delays or inability to perform due to circumstances beyond our reasonable control, including but not limited to: acts of God, natural disasters, government regulations, labor disputes, material shortages, or public health emergencies. We will make reasonable efforts to minimize delays and communicate with customers about revised timelines.

11. Governing Law

These Terms are governed by the laws of the State of Nevada and applicable federal laws. Any legal proceedings must be brought in the appropriate courts of Clark County, Nevada. If any provision of these Terms is found to be unenforceable, the remaining provisions will continue in full force and effect.

12. Modifications to Terms

OMNIMAX LLC reserves the right to modify these Terms at any time. Updated Terms will be posted on our website with a new effective date. Existing contracts will remain governed by the Terms in effect at the time of contract signing. Continued use of our services after Terms modifications constitutes acceptance of the updated Terms.

13. Contact Information

For questions about these Terms of Service or to discuss your project needs, please contact us: